Terms and Conditions

Welcome to Outdoor Living of Dallas. By using our website, services, or engaging with us in any way, you agree to the following terms and conditions. Please read them carefully.

• You agree to use our website for lawful purposes only.
   
• You may not copy, modify, or distribute content from our website without written permission.
   
• Information on our site is provided for general purposes and may be updated or changed without notice.
   

• All quotes and estimates are provided based on the information available at the time.
   
• Final pricing may vary depending on project details, site conditions, material availability, or changes requested by the client.
   
• We reserve the right to adjust pricing as necessary to reflect these changes.
   

• We work hard to complete projects on schedule, but timelines may be impacted by factors such as weather, permitting, material delays, or other circumstances outside our control.
   
• Outdoor Living of Dallas is not liable for delays caused by such events.
   

• Payment terms will be clearly outlined in your contract before work begins.
   
• Late payments may be subject to fees or suspension of work until the balance is resolved.
   

• We stand by the quality of our work and may provide warranties as specified in your project contract.
   
• Outdoor Living of Dallas is not responsible for damages caused by misuse, neglect, or modifications made after project completion.
   
• To the fullest extent permitted by law, we are not liable for indirect, incidental, or consequential damages.
   

• We may use trusted contractors, vendors, or service providers to complete portions of your project.
   
• While we work only with vetted professionals, we are not responsible for issues arising from their independent actions.
   

• By using our website, you acknowledge that cookies, pixels, and similar tools may be used for analytics and advertising (see our Privacy Policy for details).
   

We reserve the right to decline or terminate services if a client violates these terms, engages in unlawful conduct, or fails to make payments as agreed.

9.  SMS Terms & Conditions 

By providing your phone number and opting in, you consent to receive SMS/text messages from Outdoor Living of Dallas. These messages may include appointment confirmations, project updates, service information, promotions, and follow-up communications.

• Message frequency may vary.
• Message and data rates may apply.
• Consent to receive SMS messages is not a condition of purchase.
• You may opt out at any time by replying STOP to any message.
• For help, reply HELP or contact us directly.
  

We do not sell your mobile information with third parties for marketing or promotional purposes.

These Terms & Conditions are governed by the laws of the State of Texas. Any disputes will be resolved in the courts of Dallas County, Texas.